Telephone:
Date:
Dealer (full name):** (hereinafter a)
Contractor (full name): *** (hereinafter b)
In accordance with the law on contracts of the republic of china*, the law on construction of the republic of china* and other relevant laws and administrative regulations, and in accordance with the principles of equality, voluntariness, fairness and good faith, the parties agreed upon the conclusion of this contract on the construction of the electrical welding works。
I. Overview of the project
Name of project: ** secondary school welding maintenance
2. Place of construction: school* poles and ping-pong courts。
Ii. Scope and contracting methodology
1. Contract scope: maintenance and repair of the school main road east rail fence; eight table tennis billboards for welding。
Contract: this works are contracted by party b in the form of charter works, packages, charter days, package quality and safety-class construction。
Iii. Contractual period
Date of commencement of work on the earth: 10 november 2014
2. Term requirements: one month's projected duration。
Iv. Quality standards
1. Engineering quality standards: work is performed in accordance with the specifications and subject to the requirements of party a。
2. Accidents arising from the construction of b are borne by b。
3. Party b must prepare the construction safety plan, which must be approved by party a。
Within three days of this contract, each party shall pay a quality assurance fee of usd 1,000 to party a。
V. Contract price
All works under this contract are valued at the winning budget price and are not subject to unauthorized price increases, and the actual total price of the works is not greater than the winning price and is not borne by party a。
Vi. Methodology:
1. Party b shall provide party a with an amount corresponding to the construction of the project*, otherwise the party a is entitled to delay payment and is not considered to be in breach of its obligations。
(b) the completion of the work and the payment of 70 per cent of the total amount of the works for b and the return of the bond;
Vii. Completed acceptances
The completion acceptances referred to in this contract are those confirmed by a's signature and the adoption dates specified in the completion acceptances* of the work within this contract。
Performance bonds, default liabilities
1. A party shall be entitled to terminate this contract and be held fully liable to it if:
(b) if b has stopped work for more than three days without cause and has not returned to work at the request of a; safety, quality or failure to comply with contractual requirements due to a safety or quality accident on the side of b, or to the failure to effect an effective rehabilitation programme on the side of a on notice; in addition to being held responsible, party a must pay 15 per cent of the value of the contract; other serious breaches of contract or serious impairment of interests of party a。
2. After the termination of the contract by a, b may not claim payment or return for any reason whatsoever, and a is entitled to claim from b all the resulting losses。
9. This contract shall be subject to separate consultations and an agreed term shall stand at the same time as this contract。
This contract shall enter into force on signature and deposit of the bond in one part, part a and part b。
A (signature):
Representative of a legal person:
Underwriter b:
A (hereinafter: a)
B: (hereinafter: b)
This contract is concluded by consensus on the maintenance of the house in accordance with the law on contracts of the republic of china*, the regulations on the quality of construction works and other relevant laws and administrative regulations, and in accordance with the principles of equality, voluntarism, fairness and good faith。
I. Overview of the project
Name of project: building maintenance works。
2. Place of construction:。
3 scope of work: this project covers the construction of parts of the residential building, leaks in the exterior wall, and the maintenance of the interior wall, sheds, etc., as set out in the annex: technical contact sheet for the volume of work, signed jointly by the a and b parties and supervisors。
4. Contract period: 200 days from the commencement date and 200 days from the completion date, including statutory holidays, cross-construction and waiting times to accompany construction. The construction was affected by weather or other factors, and the duration of the work could be extended as appropriate by the consent of party a。
Ii. Form of engineering services
Chartered workers, packages, term of work, quality of packages。
Settlement
The first and second parties, as well as the supervisor, will need to maintain the parts and the amount of the works, which will be signed in the form of a technical contact sheet, which will be based on the contents of the technical contact list confirmed by the signature of the first and the second parties and the supervisor, and which will be settled on the basis of a 20-year quota for the city of * to determine the total cost of the works。
The parties attached as an annex to the contract a copy of the settlement signed by the parties and a technical contact list of the quantities of work jointly signed by the parties and the supervisors。
Total cost of work
It is tentatively set at us$ * million (finally based on the settlement value confirmed by parties a and b)。
V. Quality monitoring and inspection and acceptance of works
In carrying out the work, which shall be carried out in strict conformity with the state, industry standards and the rules of the enterprise and as agreed in this contract, and shall be subject to inspection by a at all times, and shall facilitate inspection and inspection. In the case of questions raised by a, the b shall perform the overhaul in a timely manner. Upon completion of the maintenance work, the work shall be inspected jointly by the a and b parties and the owner of the house under repair, which shall be subject to the three-party signature confirmation of the construction records. At the time of completion of the acceptance, party b was responsible for the continued maintenance, as required by party a, of the quality of the unrehabilitated works identified by either party a or the owner and for the overdue liability。
Vi. Proceedings
1 the payment for the works is made by cheque。
2. Within three days of the signing of the contract and the official commencement of work by party b, party a pays 30 per cent of the total construction price of the provisional works by party b。
3. The completion of the work and its acceptance and acceptance shall be completed and a settlement report shall be submitted by party b to party a within fifteen days of the project's commissioning, and the parties shall settle the matter in accordance with the criteria agreed in this contract and, after confirmation by party a, pay to party b 60 per cent of the settlement value。
Following a rainy season, no leakages or accoutrements were detected in parts of the b and a paid 95 per cent of the settlement value to b by 20 years。
The remaining 5 per cent of the works were retained as warranty payments and the balance of the warranty was returned to party b within 10 days of the expiry of the warranty period without any quality problems。
At the same time that each payment is made by a, b shall issue an equivalent amount* to a, who otherwise is entitled to refuse payment。
Vii. Positions
1. Upon completion of the work on the b side, the b side is required to assume warranty responsibility for the entire work for a period of five years, calculated from the date of completion of the work and acceptance and delivery to a。
2. The warranty for the works is 5 per cent of the amount of the works, and within 10 days of the expiry of the warranty period, the remaining portion of the warranty is returned interest-free。
3. During the warranty period, if there is a quality problem with the maintenance work, the party shall ensure that an inspection and repair is carried out within two hours of receiving notification from party a and shall be completed within a reasonable period of time to be determined by party a, and that, in the event of a delay in the performance of the repair or secondary maintenance, the party shall have the right to entrust another person for the maintenance, the cost of which shall be borne by party b and the resulting loss to party a。
In the construction work, which must be carried out strictly in accordance with the requirements of the construction process,* and in the event of further deterioration or leakage, the party shall, within two days of receiving notification from party a, repair the work and bear all the consequences and financial compensation arising from the recurrence of the problem. Such as household renovations, compensation for damage to goods, etc。
5. During the warranty period, party b shall make regular visits to the construction works, keep a record of the return visits and address in a timely manner the quality of the risks. The written address and telephone number of the head of the warranty is reserved for b to notify b for maintenance。
Name of the person responsible for the warranty on the b side: contact: address: postal code:
Responsibility for non-compliance
1. Each day after the delay in the commencement, completion or fulfilment of the other obligations, party b shall pay to party a the amount of the sum of the provisional construction price,5 and any delay of up to seven days or more, including three times, shall entitle party a to be discharged from the contract and party b to bear all of the resulting losses of party a (including compensation thus paid by party a to third parties, breach of contract)。
2. Party b shall have the right to terminate the contract for more than two days, including two days, provided that it has ceased work without permission from party a, and that party b shall withdraw without conditions within two days, and that both parties shall settle the settlement after the party has withdrawn。
3. If any of the other obligations under this contract have been breached by a party which has been corrected by notice of a period of time within which it has not been so corrected, that party is entitled to terminate this contract and that party shall bear all of the resulting losses of that party。
4. The right to recover compensation for the b party shall be available for two years from the date known to the a party or to the owner, irrespective of whether the work was approved, delivered for use and exceeded the warranty period, if the material and the construction process that was intentionally or negligently caused by b party did not comply with technical norms and environmental requirements or was inconsistent with the contract。
5. Party b may not assign rights or obligations under this contract to another person without the written consent of party a, who otherwise is entitled to terminate the contract。
Until the issue of the quality of the works that arose in the parts that were repaired by b is resolved, a is entitled to refuse to make any payment。
7. Where a breach of contract results in a termination of this contract by reason of b, b shall bear 10 per cent of the provisional price of the contract
Where the liquidated damages are not sufficient to compensate for the losses suffered by party a (including compensation thus paid by party a to third parties, liquidated damages), party b should also compensate party a for the losses suffered。
Ix. Safe construction
Under the relevant provisions, party b is responsible for the accident and the resulting costs and consequences resulting from its inadequate security measures, and party b is responsible for the physical safety of the construction personnel. Party b shall purchase personal accident insurance for the construction personnel and all insurance related to the construction work. B is responsible for any safety or other liability incident occurring during the construction process。
X. Construction responsibility
1. A party shall provide water, electricity, etc. To b in the construction of b and shall be responsible for coordination with the household and its subordinate authorities. (b) construction as required by the construction process。
2. The b side shall, in the course of the construction work, protect the square brick troupe and grass trees in the sector and shall not be damaged. In the case of household maintenance, strict compliance with the property regime, and in the event of a complaint from the household or damage from the b, the a party is entitled to deduct from the works payable to the b。
3. Party b is designated as the site representative for this project and is required to organize the work under this contract in such a way as to preserve, preserve and fulfil the terms of this contract. It is also responsible for communicating and communicating with party a, which is responsible for any commitments, assurances, correspondence, signature, confirmation, etc. Made by the person responsible to party a with respect to this project。
4. Party b carries out the work in strict compliance with the construction practices and quality standards identified by party a and keeps records of quality inspections. The construction codes, safety* protocols, fire safety provisions, environmental protection provisions are strictly enforced to ensure that the works meet the contractual requirements and those of a。
5. All facilities and works and semi-finished works on the site are protected and covered at the expense of the party b prior to completion and delivery。
6. Each day during maintenance, waste must be collected at a designated site on the one side, kept clean of the construction site and removed within the time requested by the one side, and sanitary cleaning and disposal should be completed, otherwise the latter is entitled to entrust the clean-up, the costs incurred by the one on the other side are deducted from the works due to the other on the other side。
7. To be subject at all times to quality inspection, inspection and supervision by representatives of a and his or her assigned staff, to facilitate inspection, inspection and supervision, and to return to work, modify and assume costs for reasons of their own。
8. All approvals required for the construction of maintenance work (i. E., projects for which approval is required in accordance with the relevant laws and regulations) are handled by and at the expense of party b, which bears all responsibility。
9. The maintenance work under this contract shall be performed by party b on its own initiative, which shall not subcontract, subcontract or entrust the work to any other third person without the consent of party a, who shall otherwise be entitled to terminate the contract。
10. In the course of the maintenance, care shall be taken to maintain good communication with the maintenance owner and to avoid disputes, such as where a loss is suffered by party a as a result of a dispute between party b and the maintenance owner, party b shall be liable and party a shall be entitled to deduct from the works payable to party b and party a shall be entitled to recover compensation from party b。
11. B. In the course of the maintenance and construction work, care shall be taken to protect the property, goods and property of the a and the owner and to refrain from damage to buildings and related facilities and equipment in the small area. In the case of maintenance works, party b shall compensate any damage caused to the person or property of either a party or a third person by reason of that party. A party is entitled to deduct from the works payable to b, and less than a part of a, the owner or the rights holder concerned is entitled to recover from b。
Xi. Other
1. Where the project involves confirmation of the price of the project, the confirmation shall be valid upon confirmation by the a representative, budget department of a, and upon the inclusion of the a official seal, and the signature or absence of any of the foregoing (other than the legal representative) shall not be accepted by a。
2. If the amount of work involved is confirmed, it shall be valid only if signed jointly by the representative of a and the manager of the ministry of works and if a special stamp for the visa is attached to a。
A, b and a, and a technical contact list of the volume of work jointly signed by the parties and the supervisors shall have the same legal effect as this contract。
4. This contract shall enter into force on the date on which both parties signed the stamp。
5. The dispute between the parties shall be settled amicably and in good faith. No consultations were possible and the maintenance work was referred to the court。
A: b: seal (cap)
Statutory representative: statutory representative:
(signature)
Authorized representative: authorized representative:
(signature)
Date of signature: 20 years
